Loading...
HomeMy WebLinkAboutD- 6 Agrmt for completion of Public Impr 54057-3CONSENT CALENDAR D-16 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: TITO HAES, ASSISTANT CITY MANAGER/PUBLIC WORKS DIRECTOR VIA: JAMES MAKSHANOFF, CITY MANAGER DATE: SEPTEMBER 3, 2013 SUBJECT: FINAL TRACT MAP 54057-3 RECOMMENDED ACTION It is recommended that the City Council acts and finds as follows: 1. That this project complies with the General Plan and is consistent with the approved tentative map and any amendments thereto. 2. The City Council approves and authorizes the City Manager to execute the attached AGREEMENT FOR COMPLETION OF PUBLIC IMPROVEMENTS for Tract No. 54057-3 to construct the required public improvements and also accept the attached Faithful Performance Bond in the amount of $759,900, the attached Labor and Materials Bond for $759,900, as guaranteed by Philadelphia Indemnity Insurance Company, and cash Monument Bond in the amount of $26,000. 3. That pursuant to Section 66436(a)(3)(A)(i-vii) of the Subdivision Map Act, the City Council hereby finds that the development of the property, in the manner set forth on the subject division of land, will not unreasonably interfere with the free and complete exercise of the easements held by Southern California Edison Company, Monrovia Nursery Company, Southern California Gas Company, San Gabriel Municipal Water District and Antonio and Lupe Figueroa, and accepts the map without the signatures of said easement holders. 4. This project will not violate any of the provisions of Sections 66473.5, 66474.1, and 66474.6 of the Subdivision Map Act. 5. Approve Final Tract Map No. 54057-3 and accept the offers of dedication shown on said Map. 6. Accepts the grants in Fee Simple of Lots A and M for public parks purposes. 7. The City Clerk is hereby authorized to endorse on the face of the map the certificates, which embodies the approval of said maps and acceptance of dedications. BACKGROUND This Final Map involves the approval of the final subdivision map designated 54057-3, located in the easterly portion of the project area. The Design Review for this subdivision, known as Avenswood, was approved by the Planning Commission on February 27, 2013, and includes two separate tracts, 54057-3 and 54057-12. The Final Map and bonds for the latter tract was approved by the City Council on July 15,20 13. Avenswood will feature detached single family homes ranging from 2,600 sq. ft. to over 3,000 sq. ft. The developer is TRI Pointe Homes, Inc., a Delaware Corporation, and the Civil Engineer is RBF Consulting. The designated City Engineer has completed final checking procedures for the final map and has found that it is in substantial conformance with the State Subdivision Map Act, City of Azusa requirements, Vesting Tentative Map 54057, Tentative Map 62150, and related conditions of approval. The Applicant has submitted the checked Final Map, the subdivision agreement, posted necessary bonds, and paid the applicable fees. Attached is an AGREEMENT FOR COMPLETION OF PUBLIC IMPROVEMENTS for Tract No. 54057- 3 to construct the required public improvements, as well as a Faithful Performance Bond in the amount of $759,900, and Labor and Materials Bond in the amount of $759,900 as guaranteed by Philadelphia Indemnity Insurance Company. A cash monument bond in the amount of $26,000 has also been posted. With the technical review having been completed, and the map meeting State and City requirements, the Council's approval would be a ministerial action. FISCAL IMPACT The fiscal impact of the Rosedale project was analyzed in a Fiscal Impact Study approved as part of the original Rosedale entitlements in 2003. Attachment: Agreement for Completion of Public Improvements 0) - This page is part of your document - DO NOT DISCARD 20131443542 Recorded/Filed in Official Records Recorder's Office, Los Angeles County, California 10/07/13 AT 09:16AM P0047 FEES: 0.00 TAXES: 0.00 OTHER: 0.00 PAID: 0.00 Illlil II IIIIB II 1111111 VI 1111111 AI IIIWII II I III III IIIAII II 11161111 1111111 II IIII LEADSHEET 11111111111111111111111111111111111111111111111111111111111 201310072970027 00008336464 II�YIIVI�IIdIIIIWIIII 005798104 SEQ: 01 DAR - Mail (Hard Copy) IIIIIBII911111V�III�IIIIgllllulllllln911111 -THISFORM IS NOT TO BE DUPLICATED IIVIIIIIIIII�HIIIIIIIIElIIIB1111111090�0 - RECORDING REQUESTE WHEN aroa Eo .Io,T �����W���� Jeffrey Lawrence Cornejo City Clerk City of Azusa 213 E. Foothill Blvd. Azusa, CA 91702 SPACE ABOVE THIS LINE RESERVED FOR RECORDER'S USE TITLES) Agreement for Completion of Public Improvements, Tract No. 54057-3, between City of Azusa and TRI Ponte Homes, Inc. RECORDING REQUESTED BY: WHEN RECORDED RETURN TO: CITY OF AZUSA 213 E. Foothill Blvd Azusa CA 91702 ATTN: city clerk SPACE ABOVE THIS LINE FOR RECORDER'S USE Exompt from l000rding fee r Govemmenj Code Section 6103 CITY OF AZUSA, CALIFORNIA CII City rAe � C� AGREEMENT FOR COMPLETION OF PUBLIC IMPROVEMENTS TRACT NO. 54057-3 between CITY OF AZUSA a California municipal corporation and TRI POINTE HOMES, INC. a Delaware Corporation ORANGEVVMIARTINEZ\33457. I fly 4 AGREEMENT FOR COMPLETION OF PUBLIC IMPROVEMENTS TRACT MAP NO. 54057-3 AGREEMENT FOR COMPLETION OF PUBLIC IMPROVEMENTS TRACT MAP NO. 54057-3 I. PARTIES AND DATE. This Agreement for the Completion of Public Improvements ("Agreement") is entered into as of this 50 day of Se4otbe{2013 by and between the City of Azusa, a California municipal corporation ("City") and TRI Pointe Homes, INC., a Delaware Corporation with it's principal office located at 19520 Jamboree Road, Suite 200, Irvine CA 92612 ("Developer"). City and Developer are sometimes hereinafter individually referred to as "Parry" and hereinafter collectively referred to as the "Parties." II. RECITALS. A. Developer has heretofore submitted to City an application for approval of a tract map for real property located within City, a legal description of which is attached hereto as Exhibit "A" ("Property"), and which is identified in City records Tract Map No. 54057-3. B. Developer's application for a tentative tract map for Tentative Tract No. 54057-3 was conditionally approved by the Planning Commission on February 3, 2003. C. Developer has not completed all of the work or made all of the public improvements required by Chapter 66, Article V of the Azusa Municipal Code, the Subdivision Map Act (Government Code sections 66410 et seq.), the conditions of approval for Tract No. 54057-3 or other ordinances, resolutions, or policies of City requiring construction of improvements in conjunction with the subdivision of land. D. Pursuant to Section 66-4650) and the applicable provisions of the Map Act, Developer and City enter into this Agreement for the timely construction and completion of the public improvements and the furnishing of the security therefore, acceptable to the City Engineer and City Attorney, for Tract No. 54057-3. E. Developer's execution of this Agreement and the provision of the security are made in consideration of City's approval of the final map for Tract No. 54057-3. III. TERMS. 1.0 Effectiveness. This Agreement shall not be effective unless and until all three of the following conditions are satisfied: (a) Developer provides City with security of the type and in the amounts required by this Agreement; (b) Developer executes and records this Agreement in the Recorder's Office of the County of Los Angeles; (c) the City Council of the City ("City Council") approves the final map for Tract No. 54057-3 and (d) Developer records the final map for Tract No. 54057-3 in the Recorder's Office of the County of Los Angeles. If the above ORANGEMMARTMZ\33457. 12 V1 described conditions are not satisfied, this Agreement shall automatically terminate without need. of further action by either City or Developer, and Developer may not thereafter record the final map for Tract No. 54057-3. 2.0 Public Im rovements. Developer shall construct or have constructed at its own cost, expense, and liability all improvements required by City as part of the approval of Tract No. 54057-3, including, but not limited to, all grading, roads, paving, curbs and gutters, pathways, storm drains, sanitary sewers, utilities, drainage facilities, traffic controls, landscaping, street lights, and all other required facilities as shown in detail on the plans, profiles, and specifications which have been prepared by or on behalf of Developer for Tract Map No. 54057- 3 ("Public Improvements"). The Public Improvements are more specifically described in Exhibit "B," which is attached hereto and incorporated herein by this reference. Construction of the Public Improvements shall include any transitions and/or other incidental work deemed necessary for drainage or public safety. The Developer shall be responsible for the replacement, relocation, or removal of any component of any irrigation water system in conflict with the construction or installation of the Public Improvements. Such replacement, relocation, or removal shall be performed to the complete satisfaction of the City Engineer and the owner of such water system. Developer further promises and agrees to provide all equipment, tools, materials, labor, tests, design work, and engineering services necessary or required by City to fully and adequately complete the Public Improvements. 2.1 Prior Partial Construction of Public Improvements. Where construction of any Public Improvements has been partially completed prior to this Agreement, Developer agrees to complete such Public Improvements or assure their completion in accordance with this Agreement. 2.2 Permits, Notices,• Utilit Statements. Prior to commencing any work, Developer shall, at its sole cost, expense, and liability, obtain all necessary permits and licenses and give all necessary and incidental notices required for the lawful construction of the Public Improvements and performance of Developer's obligations under this Agreement. Developer shall conduct the work in full compliance with the regulations, rules, and other requirements contained in any permit or license issued to Developer. Prior to commencing any work, Developer shall file a written statement with the City Clerk and the City Engineer, signed by Developer and each utility which will provide utility service to the Property, attesting that Developer has made all deposits legally required by the utility for the extension and provision of utility service to the Property. 2.3 Pre-approval.of Plans and S ecifications. Developer is prohibited from commencing work on any Public Improvement until all plans and specifications for such Public Improvement have been submitted to and approved by the City Engineer, or his or her designee. Approval by the City Engineer shall not relieve Developer from ensuring that all Public Improvements conform with all other requirements and standards set forth in this Agreement. 2.4 Quality of Work,• Compliance With Laws and Codes. The construction plans and specifications for the Public Improvements shall be prepared in accordance with all applicable federal, state and local laws, ordinances, regulations, codes, standards, and other ORANGE\MMARTMEZl33457. 13 requirements. The Public Improvements shall be completed in accordance with all approved maps, plans, specifications, standard drawings, and special amendments thereto on file with City, as well as all applicable federal, state, and local laws, ordinances, regulations, codes, standards, and other requirements applicable at the time work is actually commenced., 2.5 Standard of Performance. Developer and its contractors, if any, shall perform all work required to construct the Public Improvements under this Agreement in a skillful and workmanlike manner, and consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Developer represents and maintains that it or its contractors shall be skilled in the professional calling necessary to perform the work. Developer warrants that all of its employees and contractors shall have sufficient skill and experience to perform the work assigned to them, and that they shall have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the work, and that such licenses, permits, qualifications and approvals shall be maintained throughout the term of this Agreement. 2.6 Alterations to Improvements. The Public Improvements in Exhibit `B" are understood to be only a general designation of the work and improvements to be done, and not a binding description thereof. All work shall be done and improvements made and completed as shown on approved plans and specifications, and any subsequent alterations thereto. If during the course of construction and installation of the Public Improvements it is determined that the public interest requires alterations in the Public Improvements, Developer shall undertake such design and construction changes as may be reasonably required by City. Any and all alterations in the plans and specifications and the Public Improvements to be completed may be accomplished without giving prior notice thereof to Developer's surety for this Agreement. 3.0 Maintenance of Public improvements unci Landscaping. City shall not be responsible or liable for the maintenance or care of the Public Improvements until City approves and accepts them. City shall exercise no control over the Public Improvements until accepted. Any use by any person of the Public Improvements, or any portion thereof, shall be at the sole and exclusive risk of the Developer at all times prior to City's acceptance of the Public Improvements. Developer shall maintain all the Public Improvements in a state of good repair until they are completed by Developer and approved and accepted by City, and until the security for the performance of this Agreement is released. Maintenance shall include, but shall not be limited to, repair of pavement, curbs, gutters, sidewalks, signals, parkways, water mains., and sewers; maintaining all landscaping in a vigorous and thriving condition reasonably acceptable to City; removal of debris from sewers and storm drains; and sweeping, repairing, and maintaining in good and safe condition all streets and street improvements. It shall be Developer's responsibility to initiate all maintenance work, but if it shall fail to do so, it shall promptly perform such maintenance work when notified to do so by City. If Developer fails to properly prosecute its maintenance obligation under this section, City may do all work necessary for such maintenance and the cost thereof shall be the responsibility of Developer and its surety under this Agreement. City shall not be responsible or liable for any damages or injury of any nature in any way related to or caused by the Public Improvements or their condition prior to acceptance. ORANGE\MMARTINEZ\33457. 14 h 4.0 Construction Schedule. Unless extended pursuant to this Section 4.1 of this Agreement, Developer shall fully and adequately complete or have completed the Public Improvements within twelve (12) months following approval of the final map for Tract No. 54057-3. 4.1 Extensions. City may, in its sole and absolute discretion, provide Developer with additional time within which to complete the Public Improvements. It is understood that by providing the security required under Section 13.0 et seq. of this Agreement, Developer and its surety consent in advance to any extension of time as may be given by City to Developer, and waives any and all right to notice of such extension(s). Developer's acceptance of an extension of time granted by City shall constitute a waiver by Developer and its surety of all defense of laches, estoppel, statutes of limitations, and other limitations of action in any action or proceeding filed by City following the date on which the Public Improvements were to have been completed hereunder. In addition, as consideration for granting such extension to Developer, City reserves the right to review the provisions of this Agreement, including, but not limited to, the construction standards, the cost estimates established by City, and the sufficiency of the improvement security provided by Developer, and to require adjustments thereto when warranted according to City's reasonable discretion. 4.2 Accrual of Limitations Period. Any limitations period provided by law related to breach of this Agreement or the terms thereof shall not accrue until Developer has provided the City Engineer with written notice of Developer's intent to abandon or otherwise not complete required or agreed upon Public Improvements. 5.0 Grp. Developer agrees that any and all grading done or to be done in conjunction with construction of the Public Improvements or development of Tract No. 54057-3 shall conform to all federal, state, and local laws, ordinances, regulations, and other requirements, including City's grading regulations. In order to prevent damage to the Public Improvements by improper drainage or other hazards, the grading shall be completed in accordance with the time schedule for completion of the Public Improvements established by this Agreement, and prior to City's approval and acceptance of the Public Improvements and release of the Security as set forth in Section 13.0 et seq. of this Agreement. 6.0 Utilities. Developer shall provide utility services, including water, power, gas, and telephone service to serve each parcel, lot, or unit of land within Tract No. 54057-3 in accordance with all applicable federal, state, and local laws, rules, and regulations, including, but not limited to, the regulations, schedules and fees of the utilities or agencies providing such services. Except for commercial or industrial properties, Developer shall also provide cable television facilities to serve each parcel, lot, or unit of land in accordance with all applicable federal, state, and local laws, rules, and regulations, including, but not limited to, the requirements of the cable company possessing a valid franchise with City to provide such service within City's jurisdictional limits. All utilities shall be installed underground. 7.0 Fees and Charges. Developer shall, at its sole cost, expense, and liability, pay all fees, charges, and taxes arising out of construction of the Public Improvements, including, but not limited to, all plan check, design review, engineering, inspection, and other service fees, and ORANGE\MMARTINEZ\33457. 15 any impact or connection fees established by City ordinance, resolution, regulation, or policy, or as established by City relative to Tract No. 54057-3. 8.0 City Inspection of Public Improvements. Developer shall, at its sole cost, expense, and liability, and at all times during construction of the Public Improvements, maintain reasonable and safe facilities and provide safe access for inspection by City of the Public Improvements and areas where construction of the Public Improvements is occurring or will occur. 9.0 Default; Notice; Remedies. 9.1 Notice. If Developer neglects, refuses, or fails to fulfill or timely complete any obligation, term, or condition of this Agreement, or if City determines there is a violation of any federal, state, or local law, ordinance, regulation, code, standard, or other requirement, City may at any time thereafter declare Developer to be in default or violation of this Agreement and make written demand upon Developer or its surety, or both, to immediately remedy the default or violation ("Notice"). Developer shall substantially commence the work required to remedy the default or violation within ten (10) days of the Notice. If the default or violation constitutes an immediate threat to the public health, safety, or welfare, City may provide the Notice verbally, and Developer shall substantially commence the required work within twenty-four (24) hours thereof. Immediately upon City's issuance of the Notice, Developer and its surety shall be liable to City for all costs of construction and installation of the Public Improvements and all other administrative costs expenses as provided for in Section 10.0 of this Agreement. 9.2 Failure to Remed. Qi1y Action. If the work required to remedy the noticed default or violation is not diligently prosecuted to a completion acceptable to City within the time frame contained in the Notice, City may complete all remaining work, arrange for the completion of all remaining work, and/or conduct such remedial activity as in its sole and absolute discretion it believes is required to remedy the default or violation. All such work or remedial activity shall be at the sole and absolute cost, expense, and liability of Developer and its surety, without the necessity of giving any further notice to Developer or surety. City's right to take such actions shall in no way be limited by the fact that Developer or its surety may have constructed any, or none of the required or agreed upon Public Improvements at the time of City's demand for performance. In the event City elects to complete or arrange for completion of the remaining work and improvements, City may require all work by Developer or its surety to cease in order to allow adequate coordination by City. Notwithstanding the foregoing, if conditions precedent for reversion to acreage can be met and if the interests of City will not be prejudiced thereby, City may also process a reversion to acreage and thereafter recover from Developer or its surety the full cost and expense incurred. 9.3 Other Remedies. No action by City pursuant to Section 9.0 et seq. of this Agreement shall prohibit City from exercising any other right or pursuing any other legal or equitable remedy available under this Agreement or any federal, state, or local law. City may exercise it rights and remedies independently or cumulatively, and City may pursue inconsistent remedies. City may institute an action for damages, injunctive relief, or specific performance. ORANGE\MMARTINEZ\33457. 16 a 10.0 Administrative Costs. If Developer fails to construct and install all or any part of the Public Improvements within the time required ,by this Agreement, or if Developer fails to comply with any other obligation contained herein, Developer and its surety shall be jointly and severally liable to City for all administrative expenses, fees, and costs, including reasonable attorney's fees and costs, incurred in obtaining compliance with this Agreement or in processing any legal action or for any other remedies permitted by law. 11.0 Acceptance of Im rovements• As -Built or Record Drawin s. If the Public Improvements are properly completed by Developer and approved by the City Engineer, and if they comply with all applicable federal, state and local laws, ordinances, regulations, codes, standards, and other requirements, the City Council shall be authorized to accept the Public Improvements. The City Council may, in its sole and absolute discretion, accept fully completed portions of the Public Improvements prior to such time as all of the Public Improvements are complete, which shall not release or modify Developer's obligation to complete the remainder of the Public Improvements within the time required by this Agreement. Upon the total or partial acceptance of the Public Improvements by City, Developer shall file with the Recorder's Office of the County of Los Angeles a notice of completion for the accepted Public Improvements in accordance with California Civil Code section 3093, at which time the accepted Public Improvements shall become the sole and exclusive property of City without payment therefore. If Tract No. 54057-3 was approved and recorded as a single phase map, City shall not accept any one or more of the improvements until all of the Public Improvements are completed by Developer and approved by City. Issuance by City of occupancy permits for any buildings or structures located on the Property shall not be construed in any manner to constitute City's acceptance or approval of any Public Improvements. Notwithstanding the foregoing, City may not accept any Public Improvements unless and until Developer provides one (1) set of "as -built" or record drawings or plans to the City Engineer for all such Public Improvements. The drawings shall be certified and shall reflect the condition of the Public Improvements as constructed, with all changes incorporated therein. 12.0 WarrqpV and Guarantee. Developer hereby warrants and guarantees all Public Improvements against any defective work or labor done, or defective materials furnished in the performance of this Agreement, including a warranty and guarantee that all trees, shrubs and irrigation within the Property shall survive, with reasonable maintenance, in a vigorous and thriving condition reasonably acceptable to City, for a period of one (1) year following completion of the work and acceptance by City ("Warranty"). During the Warranty period, Developer shall repair, replace, or reconstruct any defective or otherwise unsatisfactory portion of the Public Improvements, including irrigation, shrubs, trees and/or transplanted trees that have died despite reasonable maintenance, in accordance with the current ordinances, resolutions, regulations, codes, standards, tree preservation plans or other requirements of City, and to the approval of the City Engineer. All repairs, replacements, or reconstruction during the Warranty periods shall be at the sole cost, expense, and liability of Developer and its surety. As to any Public Improvements which have been repaired, replaced, or reconstructed during the Warranty period, Developer and its surety hereby agree to extend the Warranty for an additional one (1) year period following City's acceptance of the repaired, replaced, or reconstructed Public Improvements. Nothing herein shall relieve Developer from any other liability it may have under federal, state, or local law to repair, replace, or reconstruct any Public Improvement following expiration of the Warranty or any extension thereof. Developer's warranty obligation ORANGE\NIM TMEZ\33457.17 E under this section shall survive the expiration or termination of this Agreement. In addition, nothing contained herein shall impose upon Developer additional maintenance obligations for any Public Improvements that are repaired, replaced or reconstructed once these are accepted by City. 13.0 Security; Surety Bonds. Prior to execution of this Agreement, Developer shall provide City with surety bonds in the amounts and under the terms set forth below ("Security"). The amount of the Security shall be based on the City Engineer's approximation of the actual cost to construct the Public Improvements, including the replacement cost for all landscaping ("Estimated Costs"). If City determines, in its sole and absolute discretion, that the Estimated Costs have changed, Developer shall adjust the Security in the amount requested by City. Developer's compliance with this provision (Section 13.0 et sem.) shall in no way limit or modify Developer's indemnification obligation provided in Section 16.0 of this Agreement. 13.1 Perfo=ance Bond. To guarantee the faithful performance of the Public Improvements and all the provisions of this Agreement, to protect City if Developer is in default as set forth in Section 8.0 et sem. of this Agreement, and to secure Developer's one-year guarantee and warranty of the Public Improvements, including the maintenance of all landscaping in a vigorous and thriving condition, Developer shall provide City a faithful performance bond in the amount of Seven Hundred and Fifty Nine Thousand Nine Hundred Dollars ($759,900), which sum shall be not less than one hundred percent (100%) of the Estimated Costs. The City Council may, in its sole and absolute discretion and upon recommendation of the City Engineer, partially release a portion or portions of the security provided under this section as the Public Improvements are accepted by City, provided that Developer is not in default on any provision of this Agreement or condition of approval for Tract No. 54057-3, and the total remaining security is not less than twenty-five percent (25%) of the Estimated Costs. All security provided under this section shall be released at the end of the Warranty period, or any extension thereof as provided in Section 12 of this Agreement, provided that Developer is not in default on any provision of this Agreement or condition of approval for Tract No. 54057-3. 13.2 Labor & Material Bond. To secure payment to the contractors, subcontractors, laborers, material men, and other persons furnishing labor, materials, or equipment for performance of the Public Improvements and this Agreement, Developer shall provide City a labor and materials bond in the amount of Seven Hundred and Fifty Nine Thousand Nine Hundred Dollars ($759,900), which sum shall not be less than one hundred percent (100%) of the Estimated Costs. The security provided under this section may be released by written authorization of the City Engineer after six (6) months from the date City accepts the final Public Improvements. The amount of such security shall be reduced by the total of all stop notice or mechanic's lien claims of which City is aware, plus an amount equal to twenty percent (20%) of such claims for reimbursement of City's anticipated administrative and legal expenses arising out of such claims. 13.3 Additional R uirements. The surety for any surety bonds provided as Security shall have a current A.M. Best's rating of no less than A:VIII, shall be licensed to do business in California, and shall be satisfactory to City. As part of the obligation secured by the Security and in addition to the face amount of the Security, the Developer or its surety shall ORANGE\MMARTINEZ\33457. 18 A secure the costs and reasonable expenses and fees, including reasonable attorney's fees and costs, incurred by City in enforcing the obligations of this Agreement. The Developer and its surety stipulate and agree that no change, extension of time, alteration, or addition to the terms of this Agreement, the Public Improvements, or the plans and specifications for the Public Improvements shall in any way affect its obligation on the Security. 13.4 Evidence and Incorporation of Security. Evidence of the Security shall be provided on the forms set forth in Exhibit "C," unless other forms are deemed acceptable by the City Engineer and the City Attorney, and when such forms are completed to the satisfaction of City, the forms and evidence of the Security shall be attached hereto as Exhibit "C" and incorporated herein by this reference. 14.0 Monument Security. Prior to City's execution of this Agreement, to guarantee payment to the engineer or surveyor for the setting of all subdivision boundaries, lot corners, and street centerline monuments for Tract No. 54057-3 in compliance with the applicable provisions of City's Municipal and/or Development Code ("Subdivision Monuments"), Developer shall deposit cash with City in the amount of Twenty Six Thousand Dollars ($26,000), which sum shall not be less than one hundred percent (100%) of the costs of setting the Subdivision Monuments as determined by the City Engineer. Said cash deposit may be released by written authorization of the City Engineer after all required Subdivision Monuments are accepted by the City Engineer, City has received written acknowledgment of payment in full from the engineer or surveyor who set the Subdivision Monuments, and provided Developer is not in default of any provision of this Agreement or condition of approval for Tract No. 54057-3. 15.0 Lien. To secure the timely performance of Developer's obligations under this Agreement, including those obligations for which security has been provided pursuant to Sections 13 et SeMc . and 14 of this Agreement, Developer hereby creates in favor of City a lien against all portions of the Property not dedicated to City or some other governmental agency for a public purpose. As to Developer's default on those obligations for which security has been provided pursuant to Sections 13 et sem. and 14 of this Agreement, City shall first attempt to collect against such security prior to exercising its rights as a contract lienholder under this section. 16.0 Indemnification. Developer shall defend, indemnify, and hold harmless City, its elected officials, officers, employees, and agents from any and all actual or alleged claims, demands, causes of action, liability, loss, damage, or injury, to property or persons, including wrongful death, whether imposed by a court of law or by administrative action of any federal, state, or local governmental body or agency, arising out of or incident to any acts, omissions, negligence, or willful misconduct of Developer, its personnel, employees, agents, or contractors in connection with or arising out of construction or maintenance of the Public Improvements, or performance of this Agreement. This indemnification includes, without limitation, the payment of all penalties, fines, judgments, awards, decrees, attorneys fees, and related costs or expenses, and the reimbursement of City, its elected officials, officers, employees, and/or agents for all legal expenses and costs incurred by each of them. This indemnification excludes only such portion of any claim, demand, cause of action, liability, loss, damage, penalty, fine, or injury, to property or persons, including wrongful death, which is caused solely and exclusively by the negligence or willful misconduct of Agency as determined by a court or administrative body of ORANGE\MMARTMZ\33457. 19 competent jurisdiction. Developer's obligation to indemnify shall survive the expiration or termination of this Agreement, and shall not be restricted to insurance proceeds, if any, received by City, its elected officials, officers, employees, or agents. 17.0 Insurance. 17.1 Types-, Amounts. Developer shall procure and maintain, and shall require its contractors to procure and maintain, during construction of any Public Improvement pursuant to this Agreement, insurance of the types and in the amounts described below ("Required Insurance"). If any of the Required Insurance contains a general aggregate limit, such insurance shall apply separately to this Agreement or be no less than two times the specified occurrence limit. 17.1.1 General Liability. Developer and its contractors shall procure and maintain occurrence version general liability insurance, or equivalent form, with a combined single limit of not less than $1,000,000 per occurrence for bodily injury, personal injury, and property damage. 17.1.2 Business Automobile Liability. Developer and its contractors shall procure and maintain business automobile liability insurance, or equivalent form, with a combined single limit of not less than $1,000,000 per occurrence. Such insurance shall include coverage for the ownership, operation, maintenance, use, loading, or unloading of any vehicle owned, leased, hired, or borrowed by the insured or for which the insured is responsible. 17.1.3 Workers' Compensation. Developer and its contractors shall procure and maintain workers' compensation insurance with limits as required by the Labor Code of the State of California and employers' liability insurance with limits of not less than $1,000,000 per occurrence, at all times during which insured retains employees. 17.1.4 Professional Liability. For any consultant or other professional who will engineer or design the Public Improvements, liability insurance for errors and omissions with limits not less than $1,000,000 per occurrence, shall be procured and maintained for a period of five (5) years following completion of the Public Improvements. Such insurance shall be endorsed to include contractual liability. 17.2 Deductibles. Any deductibles or self-insured retentions must be declared to and approved by City. At the option of City, either: (a) the insurer shall reduce or eliminate such deductibles or self-insured retentions as respects City, its elected officials, officers, employees, agents, and volunteers; or (b) Developer and its contractors shall provide a financial guarantee satisfactory to City guaranteeing payment of losses and related investigation costs, claims, and administrative and defense expenses. 17.3 Additional Insured; Separation of Insureds. The Required Insurance shall name City, its elected officials, officers, employees, agents, and volunteers as additional insureds with respect to work performed by or on behalf of Developer or its contractors, including materials, parts, or equipment furnished in connection therewith. The Required Insurance shall ORANGE\MMARTINEZ\33457. 110 contain standard separation of insureds provisions, and shall contain no special limitations on the scope of its protection to City, its elected officials, officers, employees, agents, and volunteers. 17.4 PrimM Insurance; Waiver of Subro ation. The Required Insurance shall be primary with respect to any insurance or self-insurance programs covering City, its elected officials, officers, employees, agents, and volunteers. All policies for the Required Insurance shall provide that the insurance company waives all right of recovery by way of subrogation against City in connection with any damage or harm covered by such policy. 17.5 Certificates, Verification. Developer and its contractors shall furnish City with original certificates of insurance and endorsements effecting coverage for the Required Insurance. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. All certificates and endorsements must be received and approved by City before work pursuant to this Agreement can begin. City reserves the right to require complete, certified copies of all required insurance policies, at any time. 17.6 Term, Cancellation Notice. Developer and its contractors shall maintain the Required Insurance for the term of this Agreement and shall replace any certificate, policy, or endorsement which will expire prior to that date. All policies shall be endorsed to provide that the Required Insurance shall not be suspended, voided, reduced, canceled, or allowed to expire except on 30 days prior written notice to City. 17.7 Insurer Rating. Unless approved in writing by City, all Required Insurance shall placed with insurers licensed to do business in the State of California and with a current A.M. Best rating of at least A:VIII. 18.0 Signs and Advertising. Developer understands and agrees to City's ordinances, regulations, and requirements governing signs and advertising structures. Developer hereby agrees with and consents to the removal by City of all signs or other advertising structures erected, placed, or situated in violation of any City ordinance, regulation, or other requirement. Removal shall be at the expense of Developer and its surety. Developer and its surety shall indemnify and hold City free and harmless from any claim or demand arising out of or incident to signs, advertising structures, or their removal. 19.0 Relationship Between the Parties. The Parties hereby mutually agree that neither this Agreement, any map related to Tract No. 54057-3, nor any other related entitlement, permit, or approval issued by City for the Property shall operate to create the relationship of partnership, joint venture, or agency between City and Developer. Developer's contractors and subcontractors are exclusively and solely under the control and dominion of Developer. Nothing herein shall be deemed to make Developer or its contractors an agent or contractor of City. 20.0 General Provisions. 20.1 Authority to Entex Agreement. Each Parry warrants that the individuals who have signed this Agreement have the legal power, right, and authority make this Agreement and bind each respective Party. ORANGEMMMARTINEZ\33457. 111 1� 20.2 Cooperation, Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate, or convenient to attain the purposes of this Agreement. 20.3 Construction: References,• Ca tioins. It being agreed the Parties or their agents have participated in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days, or period for performance shall be deemed calendar days and not work days. All references to Developer include all personnel, employees, agents, and subcontractors of Developer, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement. 20.4 Notices. All notices, demands, invoices, and written communications shall be in writing and delivered to the following addresses or such other addresses as the Parties may designate by written notice: CITY: DEVELOPER: City of Azusa TRI Pointe Homes, INC P.O. Box 1395 19520 Jamboree Road, Suite 200 213 E. Foothill Blvd. Irvine CA 92612 Attn: Cily Manager Attn: Tom Grable Depending upon the method of transmittal, notice shall be deemed received as follows: by facsimile, as of the date and time sent; by messenger, as of the date delivered; and by U.S. Mail first class postage prepaid, as of 72 hours after deposit in the U.S. Mail. 20.5 Amendment-, Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties. 20.6 Waiver. City's failure to insist upon strict compliance with any provision of this Agreement or to exercise any right or privilege ' provided herein, or City's waiver of any breach of this Agreement, shall not relieve Developer of any of its obligations under this Agreement, whether of the same or similar type. The foregoing shall be true whether City's actions are intentional or unintentional. Developer agrees to waive, as a defense, counterclaim or set off, any and all defects, irregularities or deficiencies in the authorization, execution or performance of the Public Improvements or this Agreement, as well as the laws, rules, regulations, ordinances or resolutions of City with regards to the authorization, execution or performance of the Public Improvements or this Agreement. 20.7 Assignment or Transfer of Agreement. Developer shall not assign, hypothecate, or transfer, either directly or by operation of law, this Agreement or any interest herein without prior written consent of City. Any attempt to do so shall be null and void, and any assignee, hypothecatee, or transferee shall acquire no right or interest by reason of such ORANGEWWART1NEZ\33457. 112 attempted assignment, hypothecation, or transfer. Unless specifically stated to the contrary in City's written consent, any assignment, hypothecation, or transfer shall not release or discharge Developer from any duty or responsibility under this Agreement. 20.8 Binding Effect. Each and all of the covenants and conditions shall be binding on and shall inure to the benefit of the Parties, and their successors, heirs, personal representatives, or assigns. This section shall not be construed as an authorization for any Party to assign any right or obligation. 20.9 No Third PgIly Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties. 20.10 Invalidity, Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect. 20.11 Consent to Jurisdiction and Venue. This Agreement shall be construed in accordance with and governed by the laws of the State of California. Any legal action or proceeding brought to interpret or enforce this Agreement, or which in any way arises out of the Parties' activities undertaken pursuant to this Agreement, shall be filed and prosecuted in the appropriate California State Court in the County of Los Angeles, California. Each Party waives the benefit of any provision of state or federal law providing for a change of venue to any other court or jurisdiction including, without limitation, a change of venue based on the fact that a governmental entity is a party to the action or proceeding, or that a federal right or question is involved or alleged to be involved in the action or proceeding. Without limiting the generality of the foregoing waiver, Developer expressly waives any right to have venue transferred pursuant to California Code of Civil Procedure Section 394. 20.12 Attorneys' Fees and Costs. If any arbitration, lawsuit, or other legal action or proceeding is brought by one Party against the other Party in connection with this Agreement or the Property, the prevailing party, whether by final judgment or arbitration award, shall be entitled to and recover from the other party all costs and expenses incurred by the prevailing party, including actual attorneys' fees ("Costs"). Any judgment, order, or award entered in such legal action or proceeding shall contain a specific provision providing for the recovery of Costs, which shall include, without limitation, attorneys' and experts' fees, costs and expenses incurred in the following: (a) post judgment motions and appeals, (b) contempt proceedings, (c) garnishment, levy, and debtor and third party examination, (d) discovery, and (e) bankruptcy litigation. This section shall survive the termination or expiration of this Agreement. 20.13 Countemarts. This Agreement may be executed in counterpart originals, which taken together, shall constitute one and the same instrument. ORANGEMMARTINEZ\33457. 113 CITY OF AZUSA By: (signs e) (print name) City Manager City of Azusa ATTEST: By: _ ���wnature) 'O"KCC rint name) City Clerk City of Azusa TRI POINTE HOMES, INC By. - Thomas J. Mitchell President By: Thomas G. Grable President NOTE: DEVELOPER'S SIGNATURES SHALL BE DULY NOTARIZED, AND APPROPRIATE ATTESTATIONS SHALL BE INCLUDED AS MAY BE REQUIRED BY THE BYLAWS, ARTICLES OF INCORPORATION, OR OTHER RULES OR REGULATIONS APPLICABLE TO DEVELOPER'S BUSINESS ENTITY. ORANGEWMARTINEZ03457. 114 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 State of California nn County of _L A n 9-e les On-SCe-T, 14, 'x`1? before me, y, Ae4 A&vLi,,-_- z Date Here Insert Name and Title of the Officer personally appeared ,moi C-- ivL -eS 5 kip ._1t(). . ----- Name( -s -)-of Signer(s) J. V. 1111ERNAIN 0Ea Commission # 1998874 aNotary Public - California y Z Los MOWS County my Comm. Expires Nov 22, 2016 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(4 whose name(s) is/ar-e- subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/h^ ! authorized capacity(ies), and that by his/her4w& signature.(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: Signature of Notary Public 10T— OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attaches! Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: Signer's Name: .............. ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 0 2010 National Notary Association • NationalNotary org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CML CODE § 1189 State of California County of O r& h On 5I 2G 1-;5 before me, V16 -V-A 11 0 t/ e,4 6(- 1 t✓ Dale Here Insert Na a and Itle of the Officer ' personally appeared I `� �' i� � • I Le I-' �} (i YOA­ Namo(s) of Slgner(s] J. WARD Commission # 1973102 Notary Public - California Orange County L My Coram. E es Mar 24 2016 Place Notary Seal Above who proved to me on t basis of sati factory evidence to be the pers (s�� whose namEos Ware subscribed to the within instrument and acknowledged to me that iae/sWthey executed the same in hisser/their authorized capacity es , and that by bis/her/their signator [s on the instrument the persos , or the entity upon behalf of which the person s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: woup� U '� Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: - Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: _ ❑ Corporate Officer — Title(s): . ❑ Individual e ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: Signer's Name: ❑ Corporate Officer — Title(s): 1 ❑ Individual • ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: © 2010 National Notary Association • NalionalNotary, org • 1 -600 -US NOTARY (1-800-876-6827) Item #5907 EXHIBIT "A" LEGAL DESCRIPTION OF PROPERTY TRACT NO. 54057-3 ORANGE\MMARTINEZ\33457. 116 wd CLT N/bZ/b wgww )mn•wnii aiarxan -iNn»_N i iD— ,,---\ , ......,.. -.,, n LV L\V1Vuc _ .vat .� •'r� 6Sxaey i Abu •_ r o I � Aim p i m ITj tfl Zm >• N N � - q -J i ■ 0 in 1 f Nm N ,Y mCD Z D _ � m N C6 0 0 U- 0 z - OZ V � O f- cD cn i LL:D L4 O t� OSLU O O N O — O 1 J O(gp -,aN 4 D LL W ----- \ 5 ti V w cn Q �m a!0 LU jje LL Z Wo 0 -1 z EL p p m UI r W 1 aWw awe LL W P°N I 0E -LL O al O 19 V5 m LU� Gam. z a LL m O LOL \ r ¢0F \fit, Z ED a � �� I EXHIBIT "B" LIST OF PUBLIC IMPROVEMENTS TRACT NO. 54057-3 ORANGEWMARTMD33457. 117 CITY OF AZUSA BOND ESTIMATE TR. 54057-03 SUBDIVIDER: TRI Pointe Homes PROJECT NUMBER: 133055.000 CALCULATED BY: SMCOOK CHECKED BY: Okamoto DATE: April 9, 2013 ENGINEER: SMCOOK PROJECT: TTM 54057-03 BOND AMOUNT: $759,900 IMPROVEMENT BOND ESTIMATE (to be based on latest unit prices) STREET Const Notes on Imp. Plan ITEM OF WORK Total Qty. Unit Price Cost 1 4" AC Pavement over 8" AB 53,0201 Sq.Ft. @ $2.50 $132,550 2 C&G Type B 3,3701 Lin.Ft. @ $2.00 $6,740 3 Sidewalk 4" PCC 19,190 Sq.Ft. @ $3.50 $67,165 4 Drive Approach 4,365 Sq.Ft. @ $3.50 $15,278 5 Curb Ramp 10 Ea• @ $2,500.00 $25,000 6 Local Depression 11 Ea. @ $3,500.00 $38,500 7 Street Name Post and Sin 5 Ea• @ $500.00 $2,500 8 Street Light Pole and Luminaire 15 Ea. @ $4,200.00 $63,000 10 Redwood Header 28 Lin.Ft. @ $11.00 $308 11 IlRemove Redwood Header 34 Lin.Ft. @ $8.00 $272 Sub Total $351,313 :5% Contingency $17,566 STREET BOND AMOUNT $368.900 STORM DRAIN Const Notes on Imp. Plan ITEM OF WORK Total Qty. Unit Price Cost 22 24" R.C.P 850 Lin.Ft. @ $95.00 $80,750 23 18" R.C.P. 235 Lin.Ft. @ $80.00 $18,800 25 MH 5 Ea. @ $4,500.00 $22,500 27 Catch Basins 11 Ea. @ $4,800.00 $52,800 33 Remove Brick and Motar Plug 4 Ea. @ $275.00 $1,100 :sub Total $175,950 :5% Contingency $8,798 STORM DRAIN BOND AMOUNT $184,700 h:\pdata\10103800\admin\processing\bond estimates\54057-03 sipAs DOMESTIC WATER ons otes on Imp. Plan ITEM OF WORK Total Qty. Unit Price Cost 60 8" DIP 1,750 Lin.Ft. @ $43.00 $75,250 61 8" Valve 6 Ea. @ $3,200.00 $19,200 62 'Thrust Block 5 Ea. @ $1,000.00 $5,000 63 (Fire Hydrant 5 Ea. @ $3,800.00 $19.000 64 2" BO 1 Ea. @ $3,000.00 $3,000 65 Remove Temp. BO 1 jEa. @ $500.00 $500 66,71 2" Service Assembl 21 Ea. @ $500,001 $1,000 Sub Total $122,950 5% Contingency $6,148 WATER BOND AMOUNT $129.100 SEWER Const Notes on Imp. Plan ITEM OF WORK Total Qty. Unit Price Cost 40 81, VCP 1,620 Lin.Ft. @ $35.00 $56,700 41 48" Manhole 4 Ea. @ $4,000.00 $16,000 43 Install Clay Stopper 1 Ea. @ $400.00 $400 44 Remove Seal and Join Existing 1 Ea. @ $400.00 $400 Sub Total $73,500 5% Contingency $3,675 SEWER BOND AMOUNT $77,200 TOTAL IMPROVEMENT BOND AMOUNT 1 $759,900 h:\pdata\10103800\admin\processing\bond estimates\54057-03 sip,xls EXHIBIT "C" SURETY BONDS AND OTHER SECURITY TRACT NO. 54057-3 As evidence of understanding the provisions contained in this Agreement, and of the Developer's intent to comply with same, the Developer has submitted the below described security in the amounts required by this Agreement, and has affixed the appropriate signatures thereto: PERFORMANCE BOND PRINCIPAL AMOUNT: $759,900 Surety: Philadelphia Indemnity Insurance Company Attorney-in-fact: Janina Monroe Address: 231 St. Asaph's Rd., Suite 100 Bala Cynwyd PA 19004 MATERIAL AND LABOR BOND PRINCIPAL AMOUNT: $759,900 Surety: Philadelphia Indemnity Insurance Company Attorney-in-fact: Janina Monroe Address: 231 St. Asaph's Rd., Suite 100 Bala Cynwyd PA 19004 CASH MONUMENT SECURITY: $26,000 Amount deposited per Cash Receipt No. f Z ---0.3 Date: 0RANGEV,S4ARTINEZ\33457. 120 BOND NO. PB03010400709 INITIAL PREMIUM: $11,399 / Two (2) Years SUBJECT TO RENEWAL CITY OF AZUSA PARC-L/TRACT MAP NO. 54057-3 EUROVEMENTS PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: WHEREAS the City of Azusa, California ("City") and TRI Pointe Homes, Inc., a Delaware corporation ("Principal"), have executed an agreement for work consisting of, but not limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all grading, roads, paving, curbs and gutters, pathways, storm drains, sanitary sewers, utilities, drainage facilities, traffic controls, landscaping, street lights, and all other required facilities for Parcel/Tract Map No. _ 54057-3 ("Public Improvements"); WHEREAS, the Public Improvements to be performed by Principal are more particularly set forth in that certain Agreement for Completion of Public Lnprovernents dated ("Improvement Agreement'); WHEREAS, the Improvement Agre(-,ni ent is hereby referred to and incorporated herein by reference; and WHEREAS, Principal is required by the Improvement Agreement to provide a good and sufficient bond for performance of the Improvement Agreement, and to guarantee and warranty the Public improvements constructed thereunder. NOW, THEREFORE, Principal and Philadelphia Indemnity Insurance Company C"Surety"), a corporation organized and existing under the laws of the State of Pennsylvania , and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto City in the sum of ** dollars ($759,900.00----- , said sum being not less than one hundred percent (100%) of the total cost of the Public Improvements as set forth in the Improvement Agreement, we bind ourselves, aur heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. **Seven Hundred Fifty -Nine Thousand Nine Hundred and no/100** THE CONDITION OF TPIIS OBLIGATION is such, that if Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, agreements, guarantees, and warranties in the Improvement Agiccmcnt and any alteration thereof made as therein provided, to be kept and performed at the time and in the manner therein specified and in all respects according to their intent and meaning, and to indemnify and save harmless City, its officers, 0RANG9MMARTn.TRZ133457. 120 Performance Bond No. PB03010400709 Page Two (2) employees, and agents, as stipulated in the Improvement Agreement, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As part of the obligation secured hereby, and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any jndgment rendered. Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the Improvement Agreement, or to any plans, profiles, and specifications related thereto, or to the Public ImInovements to be constmcted thereunder, shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition. This bond is executed and filed to comply with Section 66499 et se,�c . of the Government: Code of California as security for performance of the Improvement Agreement and security for the one-year guarantee and wanwity of the Public Improvements. IN WITNESS WHEREOF, the seal and sigrratirre of the Principal is hereto affixed, and the corporate seal and the name of the Surety is hereto axed and attested by its duly authorized Attorney -in -Fact at Irvine, California this 29th day of April 2013 TRI Pointe Homes, Inc., a Delaware corporation Company Principal S ety �'A Preside t A+ tvzxrey-in-Fact j j,ornu,d � 1'bl 7 t i e I 1 Hina Monroe (print name) (punt name) NOTE: APPROPRIATE NOTARIAL ACKNOWLEDGMENTS OF EXECUTION BY PRINCIPAL AND SURETY, AND A COPY OF THE POWER OF ATTORNEY TO LOCAL REPRESENTATIVES OF THE BONDING COMPANY MUST BE ATTACHED TO THIS BOND. oRANGMMMART=\33457. 120 2 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL c0®E § 1189 State of California County of U r& Is - On 2 b before me, J �f GI i t �� V P LCL Pale H r Insert Name and Title the Officer personally appeared 1 r `� }��J i � I. Name(s) of Signer(s) J. WARD Commission #t 1979102 Notary Public - California 2z Orange County M Comm. Ex lyes Mar 24.201E Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the personjs) whose name�(s�is/are subscribed to the within instrument and acknowledged to me that he/shoAtielr executed the same in his/hegtheir authorized capacity(!esy, and that by his/hp-0theit— signature(s)fon the instrument the person�sy, or the entity upon behalf of which the person (q) -acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official � kal. Signature: �Vm Signature of Notary Pijblz OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing Number of Pages: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — 0 Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 0 2010 National Notary Association • NationalNotary.org • 1 -800 -US NOTARY (1-800-876-6827) _ --W �.�•�•M. _•_.- Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT STATE OF CALIFORNIA County of Orange On APR 2 9 2013 Date before me, Michelle Haase personally appeared Janina Monroe Insert Name of Notary exactly as it appears on the official seal Name(s) , Notary Public, OPTIONAL Though the information below is not required by law, it may prove valuable to persons relyinq on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s):_ ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: who proved to me on the basis of satisfactory evidence to be the person6] whose nameM is/W subscribed to the Within instrument and acknowledged to me thaW/shelth* executed the same in MherltWr authorized capacity(i , and that by Ip /her/M— signatureW on the instrument the MICHELLE HttiFiS� =�.�, personM, or the entity upon behalf of which the person(( (t` , ; a.:- Commission # 1988148 acted, executed the instrument. V Notary Public - Cally®rnis s 7 certify !cerci under PENALTY OF PERJURY under the laws of Orange Coce+ty -. the State of California that the foregoing paragraph is true Conm. y-fros Aut; 22.231 + and correct. Witness my hand and official seal. Signature Place Notary Seal Above signature,,& Notary Pull c OPTIONAL Though the information below is not required by law, it may prove valuable to persons relyinq on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s):_ ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: 165 t�J PHILADELPHIA INDEMNITY INSURANCE COMPANY .� 231 St. Asaph's Rd., Suite 100 Bala Cynwyd, PA 19004-0950 Power of Attorney KNOW ALL PERSONS BY THESE PRESENTS: that PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and appoint: JANINA MONROE, THOMAS G. MCCALL, TIMOTHY J. NOONAN AND MICHELLE HAASE OF LOCKTON COMPANIES, LLC; its true and lawful Attorney(s) in fact with full authority to execute on its behalf bonds, undertakings, recognizances and other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to exceed $5,000,000.00: This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PHILADELPHIA INDEMNITY INSURANCE COMPANY at a meeting duly called the I" day of July, 2011. RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the Company to: (1) Appoint Attomey(s) in Fact and authorize the Attorney(s) in Fact to execute on behalf of the Company bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof and to attach the seal of the Company thereto; and (2) to remove, at any time, any such Attomey-in-Fact and revoke the authority given. And, be it FURTHER RESOLVED: That the signatures of such officers and the seal of the Company may be affixed to any suclt Power of Attorney or cert ificatc relating thereto by facsimile, and any such Power of Attorney so executed and certified by facsimile signatures and facsimile seal shall be valid and biding upon the Company in the future with the respect to any bond or undertaking to which it is attached. IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS 15TH DAY OF NOVEMBER 2012. On this 15's day of November 2012, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he is the therein described and authorized officer of the PHILADELPHIA INDEhLVITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. (P Mt,4n tNt'JIL 0FPi3MULVANK l*TAIt SFAI. OMIfSUPORATH, Malas}' P11* �y LemOUR em ' Irealho�{tiE&O 20t9,_J Notary Public: residing at: (Notary Seal) My commission expires: Bala Cvnwvd,PA ar h 22 2016 I, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto are true and correct and are still in full force and effect. I do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHIL ADELPHIA INDEMNITY INSURANCE COMPANY, APR 2 9 2013 In Testimony Whereof I have subscribed my name and affixed the facsimile seal of each Company this LJ day of I 20 �. Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNITY INSURANCE COMPANY -1° }} (Seal) ....", President Sean S. Sweeney, President Philadelphia Indemnity Insurance Company On this 15's day of November 2012, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he is the therein described and authorized officer of the PHILADELPHIA INDEhLVITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. (P Mt,4n tNt'JIL 0FPi3MULVANK l*TAIt SFAI. OMIfSUPORATH, Malas}' P11* �y LemOUR em ' Irealho�{tiE&O 20t9,_J Notary Public: residing at: (Notary Seal) My commission expires: Bala Cvnwvd,PA ar h 22 2016 I, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto are true and correct and are still in full force and effect. I do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHIL ADELPHIA INDEMNITY INSURANCE COMPANY, APR 2 9 2013 In Testimony Whereof I have subscribed my name and affixed the facsimile seal of each Company this LJ day of I 20 �. Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNITY INSURANCE COMPANY BOND NO. PB03010400709 INITIAL PREMIUM: is included in Performance Bond SUBJECT TO RENEWAL CITY OF AZUSA PARCEL/TRACT MAP IMPROVEMENTS LABOR AND MATERLAL BOND KNOW ALL MEN BY THESE PRESENTS: WHEREAS the City of Azusa, California ("City") and . TRI Pointe Homes, Inc., a Delaware corporation ("Principal"), have executed an agreement for work consisting of, but not limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all grading, roads, paving, curbs and gutters, pathways, storm drains, sanitary sewers, utilities, draiilage facilities, traffic controls, landscaping, street lights, and all other required facilities for Parcf.Vl'ract Map No. 54057_3 {"Public Improvements"); WHEREAS, the Public Improvements to be perforined by Principal are more particularly set forth in that certain Agreement for Completion of Pubic Improvements dated ("Improvement Agreement"); WHEREAS, the Improvement Agreement is hereby referred to and incorporated herein by reference; and WHEREAS, Principal is required to furnish a bond in connection with the Improvement Agreement providing that if Principal or any of its subcontractors shall fail to pay for any matc.r.ials, provisions, or other supplies, or terms used in, upon, for, or 'about the performance of the Public Improvements, or for any work or labor done thereon of any kind, or for amounts due under the provisions of Title 15 (commencing with section 3082) of Part 4 of Division 3 of the California Civil Code, with respect to such work or labor, that the Surety on this bond will pay the same together with a reasonable attorney's fee in case suit is brought on the bond. Philadelphia Indemnity Insurance Company NOW, THEREFORE, Principal and ("Surety"), a corporation organized and existing under the laws of the State of Pennsylvania and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto City and to any and all material men, persons, companies or corporations furnishing materials, provisions, and other supplies used in, upon, for or about the performance of the Public Improvements, and all persons, companies or corporations renting or hiring teams, or implements or machinery, for or contributilig to the Public Improvements to be done, and all persons performing work or labor upon the same and all persons supplying both work and materials as aforesaid excepting the Principal, the sum of ** DOLLARS, ORHI4COMMAXI'DIEW3457. 120 "Seven Hundred Fify-Nine Thousand Nine Hundred and no/10044 Payment Bond No. PB03010400709 -Page Two (2) (T 759,900.00--- �, said sum being not less than 100% of the total cost of the Public improvements under the terms of the Improvement Agreement, we bind ourselves, our heirs, executors and administrators, successors and assigns jointly and severally, firmly by these presents. TIIE CONDITION OF THIS OBLIGATION IS SUCH that if the Principal, his or its subcontractors, hews, executors, administrators, successors, or assigns, shall fail to pay for any materials, provisions, or other supplies or machinery used in, upon, for or about the performance of the Public Improvements, or for work of labor thereon of any kind, or fail to pay any of the persons named in California Civil Code Section 3181, or amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such claimant, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and his subcont actors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor, and all other applicable laws of the State of California and rules and regulations of its agencies, then said Surety will pay the same in or to an amount not exceeding the sum specified herein. As part of the obligation secured hereby, and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. This bond is executed and filed to comply with Section 66499 et sec,. of the California Government Code as security for payment to contractors, subcontractors, and persons furnishing labor, materials, or equipment for construction of the Public Improvements or performance of the Improvement Agreement. It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the California Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the Improvement Agreement, or to any plans, profiles, and specifications related thereto, or to the Public Improvements to be constructed thereunder, shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition. 0RANGEWMARTINEM3457. 120 Payment Bond No. PB03010400709 Page Three (3) IN WITNESS WHEREOF, the seal and signature of the Principal is hereto affixed, and the corporate seal and the name of the Surety is hereto affixed and attested by its duly authorized Attorney -in -Fact at Irvine, California this 29th day of Aprll 2013 TRI Pointe Homes, Inc., a Delaware corporation Philadelphia Indemnity Insurance Company Principal S e President ll Augrney-in�-Fact 1 k 4vlCLS �J, tM 3 nina Monroe (print name) �— (print namme) NOTE: APPROPRIATE NOTARIAL ACKNOWLEDGMENTS OF EXECUTION BY PRINCIPAL AND SURETY, AND A COPY OF THE POWER OF ATTORNEY TO LOCAL REPRESENTATIVES OF THE BONDING COMPANY MUST BE ATTACHED TO THIS BOND. ORANGEWMAXfMEW3457. 120 CALBFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1199 State of California County of 0 q, Vt On before me, �L1. �'7I I C_ Oala N r Insert Name and Title ol the OlHcor personally appeared `FN `U Y�(Jt S J I Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persort(s) whose nameWis/are subscribed to the within instrument and acknowledged to me that he/she/they' executed the same in his/herltheir authorized capacity(josy, and that by J. CorlimissWAR i n#r01973102 his/hc4-1/their-signaiure,(,s•)�on the instrument the 14; A, -Z6" Notary Public - California zz person(4, or the entity upon behalf of which the Orange County person(sKacted, executed the instrument. LIEMUCOMM. Expires Mar 24,2016.' I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: Q�, �viu L__) Place Notary Seal Above Ff Signature d Notniy Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: . Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: _ ❑ Corporate Officer — Title(s): ❑ Individual M. ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: Signer's Name: _.... ❑ Corporate Officer — Title(s): _ _____ ❑ Individual ❑ Partner — Q Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: © — 2010 National Notary Association • NationalNotary.org • 1 -800 -US NOTARY (1-800.876-6827) — Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT STATE OF CALIFORNIA County of Orange } On APR 2 9 2013 before me, Michelle Haase Date personally appeared Janina Monroe Insert Name of Notary exactly as it appears on the official seal MICHELL' cif{P,Si f T� 196616 Not 4ry Public - California � Orange County � 4 e.-L'`#rr MY 13061riz. fl:pires Aun 22.2016 Name(s) of Signer(s) , Notary Public, who proved to me on the basis of satisfactory evidence to be the person6N whose nameM isle subscribed to the within instrument and acknowledged to me thatblshelt" executed the same in ft/her)the4r authorized capacity(io}, and that by lW*lherlthW Signature* on the instrument the personM, or the entity upon behalf of which the person(X)( acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and Signature official.1seal. —- Place Notary Seal Above Stgnatule of Not•�ary Public - OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date. Signer(s) Other Than Named Above: Capacity(les) Claimed by Signer(s) Signer's Name: _ ❑ Individual ❑ Corporate Officer—Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: 166 PHILADELPHIA INDEMNITY INSURANCE COMPANY 231 St. Asaph's Rd., Suite 100 Bala Cynwyd, PA 19004-0950 Power of Attorney KNOW ALL PERSONS BY THESE PRESENTS: that PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and appoint: JANINA MONROE, THOMAS G. MCCALL, TIMOTHY J. NOONAN AND MICHELLE HAASE OF LOCKTON COMPANIES, LLC; its true and lawful Attomey(s) in fact with full authority to execute on its behalf bonds, undertakings, recognizances and other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to exceed $5,000,000.00: This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PHILADELPHIA INDEMNITY INSURANCE COMPANY at a meeting duly called the 1" day of July, 2011. RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the Company to: (1) Appoint Attomey(s) in Fact and authorize the Attomey(s) in Fact to execute on behalf of the Company bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof and to attach the seal of the Company thereto; and (2) to remove, at any time, any such Attomey-in-Fact and revoke the authority given. And, be it FURTHER RESOLVED: That the signatures of such officers and the seal of the Company may be affixed to any such Power of Attorney or certificate relating thereto by facsimile, and any such Power of Attorney so executed and certified by facsimile signatures and facsimile seal shall be valid and biding upon the Company in the future with the respect to any bond or undertaking to which it is attached. IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS CORPORATE SEALTO BE AFFD(ED BY ITS AUTHORIZED OFFICE THIS 15TH DAY OF NOVEMBER 2012. r ' (Seal) '",:;�h,!,��,•.,;.na President Sean S. Sweeney, President Philadelphia Indemnity Insurance Company On this 15'h day of November 2012, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly swam said that he is the therein described and authorized officer of the PHILADELPHIA INDEMNITY INSURANCE COMPANY; that the seal axed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. coo L{}p67_ OFAiSiH9YL11Rt3 t1aTARK sial Of i FORM Fl myPu* �y MVYT ^ lea C2D19_ j Notary Public: residing at: (Notary Seal) My commission expires: y Bala C3mmTd. PA March 22 2016 I, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do h6rby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto are true and correct and are still in full force and effect. I do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHILADELPHIA. INDEMNITY INSURANCE COMPANY, 13 In Testimouy Whereof I have subscribed my name and affixed the facsimile seal of each Company this L--1 day of �� 20 L _ Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNITY INSURANCE COMPANY b.r .b H -�1• .y. inn i n, a.•• BOND NO. PB03010400709 INITIAL PREMIUM: $11,399 1 Two 2 Years SUBJECT TO RENEWAL CITY OF AZUSA PARCEL/TRACT MAP NO. 54057-3 IMPROVEMENTS PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: WHEREAS the City of Azusa, CaliiOrni.a ("City") and TRI Pointe Homes, Inc., a Delaware corporation ("Principal"), have executed an agreement for work consisting of, but not limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all grading, roads, paving, curbs and gutters, pathways, storm drains, sanitary sewers, utilities, drainage facilities, traffic controls, landscaping, street lights, and all other required facilities for Parcel/Tract Map No. _ . 540.57-3 ("Public Improvements"); WHEREAS, the Public Improvements to be performed by Principal are more particularly set forth in that certain Agreement for Completion of Public Improvements dated ("Improvement Agreement"); WHEREAS, the Improvement Agreement is hereby referred to and incorporated herein by reference; and WHEREAS, Principal is required by the Improvement Agreement to provide a good and sufficient bond for performance of the Improvement Agreement, and to guarantee and warranty the Public Improvements constructed tliercunder. NOW, THEREFORE, Principal and Philadelphia Indemnity Insurance Company C"Surety"), a corporation organized and existing under the laws of the State of Pennsylvania , and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto City in the sum of ** dollars ($759,900.00------- , said sum being not less than one hundred percent (100°/x) of the total cost of the Public improvements as set forth in the Improvement Agreement, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. **Seven Hundred Fifty -Nine Thousand Nine Hundred and no/100** THE CONDITION OF THIS OBLIGATION is such, that if Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, agreements, guarantees, and warranties in the Improvement Ai;recrnent and any alteration thereof made as therein provided, to be Icept and performed at the time and in the manner therein specified and in all respects according to their intent and meaning, and to indemnify and save harmless City, its officers, ORANGEMMA INEZ133457.120 Performance Bond No. PB03010400709 Page Two (2) employees, and agents, as stipulated'in the Improvement Agreement, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As part of the obligation secured hereby, and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the Improvement Agreement, or to any pians, profiles, and specifications related thereto, or to the Public Improvements to be constructed thereunder, shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition. This bond is executed and filed to comply with Section 66499 et semc� . of the Government Code of California as security for performance of the Improvement Agreement and security for the one-year guarantee and warranty of the Public Improvements. IN WITNESS WHEREOF, the seal and signature of the Principal is hereto affixed, and the corporate seal and the name of the Surety is hereto affixed and attested by its duly authorized Attorney -in -Fact at Irvine, California this 29th day of April , 2013 TRI Pointe Homes, Inc., a Delaware corporation Principal By: Preside t Ur�a� J VMS 14 11 (print name) NOTE: APPROPRIATE NOTARIAL ACKNOWLEDGMENTS BY PRINCIPAL AND SURETY, AND A COPY OF ATTORNEY TO LOCAL REPRESENTATIVES OF COMPANY MUST BE ATTACHED TO THIS BOND. OP-ANGBAMAkMEZU3457. 120 OF EXECUTION THE POWER OF THE BONDING RD CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 State of California County of rak V� i On -?,oo before me, j • vv& rel i %J l Date [ I HI, Insert Name and Title the Officer personally appeared 1 !� Cly J I `�- (5 Name(s) of Signer(s) J. WARD Commission #t 1973102 Notary Public - California Oranp County Corrlm. Ex E irss boar 24, 2016 who proved to me on the basis of satisfactory evidence to be the person(s)' whose names)-lis/are subscribed to the within instrument and acknowledged to me that he/she/they- executed the same in his/herAheir authorized capacity(ies), and that by his/hea:!their- signature(s) on the instrument the person(sj, or the entity upon behalf of which the person(Wacted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: Place Notary Seal Above _ Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above:...._ Capacity(ies) Claimed by Signer(s) Signer's Name. ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: _ Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing © 2010 National Notary Association • NationalNotary.org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT STATE OF CALIFORNIA County of Orange On APR 2 9 2013 Bate personally appeared before me, Michelle Haase Janina Monroe Commission #E 1916148 �+ Notary Public - California Orange County M9 Comm. fx ires Att22.2016t , Notary Public, Insert Name of Notary exactly as it appears on the official seal Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the personal whose nameXg, isles subscribed to the within instrument and acknowledged to me thatft/she/00;, executed the same in Mherltftr authorized capacity(iW, and that by WherltMr signatureW on the instrument the person¢, or the entity upon behalf of which the person(o acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and official seal. r. Signature Place Notary Seal Above Signature,Of Notary Public OPTIONAL Though the information below is not required by law- it may prove valuable to persons relyinq on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s). ❑ Partner ❑ Limited ❑ General ❑ Attomey in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: 165 4 PHILADELPHIA INDEMNITY INSURANCE COMPANY 1 231 St. Asaph's Rd., Suite 100 Bala Cynwyd, PA 19004-0950 Power of Attorney KNOW ALL PERSONS BY THESE PRESENTS: that PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and appoint: JANINA MONROE, THOMAS G. MCCALL, TIMOTHY J. NOONAN AND MICHELLE HAASE OF LOCKTON COMPANIES, LLC; its true and lawful Attomey(s) in fact with full authority to execute on its behalf bonds, undertakings, recognizances and other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to exceed $5,000,000.00: This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PHILADELPHIA INDEMNITY INSURANCE COMPANY at a meeting duly called the I" day of July, 2011. RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the Company to: (1) Appoint Attomey(s) in Fact and authorize the Attomey(s) in Fact to execute on behalf of the Company bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof and to attach the seal of the Company thereto; and (2) to remove, at any time, any such Attorney -in -Fact and revoke the authority given. And, be it FURTHER RESOLVED: That the signatures of such officers and the seal of the Company may be affixed to any such Power of Attorney or certificate relating thereto by facsimile, and any such Power of Attorney so executed and certified by facsimile signatures and facsimile seal shall be valid and biding upon the Company in tite future with the respect to any bond or undertaking to which it is attached. IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS 15•r" DAY OF NOVEMBER 2012. On this 15'h day of November 2012, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he is the therein described and authorized officer of the PIHLAD'E, LPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. =Z�HFII yataNavts� "t, iiFJ4LTH, Hdlaty pCoo ttyyh E yP'q'q* Notary Public: residing at: BalaC A (Notary Seal) My commission expires: March 22 2016 1, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto arc true and correct and are still in full force and effect. l do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHILADELPHIA INDEMNITY INSURANCE COMPANY, APR 2 13 9 20 In Testimouv Whereof I have subscribed my name and affixed the facsimile seal of each Company this 1 day of 1 7 1! Y 120 Lam. X27 Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNI'T'Y INSURANCE COMPANY 1�•r� ^: (Seal) .... President Sean S. Sweeney, President Philadelphia Indemnity Insurance Company On this 15'h day of November 2012, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he is the therein described and authorized officer of the PIHLAD'E, LPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. =Z�HFII yataNavts� "t, iiFJ4LTH, Hdlaty pCoo ttyyh E yP'q'q* Notary Public: residing at: BalaC A (Notary Seal) My commission expires: March 22 2016 1, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto arc true and correct and are still in full force and effect. l do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHILADELPHIA INDEMNITY INSURANCE COMPANY, APR 2 13 9 20 In Testimouv Whereof I have subscribed my name and affixed the facsimile seal of each Company this 1 day of 1 7 1! Y 120 Lam. X27 Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNI'T'Y INSURANCE COMPANY BOND NO. PB03010400709 INITIAL PREMIUM: is included in Performance Bond SUBJECT TO RENEWAL CITY OF AZUSA PARCEL/TRACT MAP IMPROVEMENTS LABOR AND MATERIAL BOND KNOW ALL MEN BY THESE PRESENTS: WHEREAS the City of Azusa, California ("City") and TRI Pointe Homes, Inc., a Delaware corporation_ ("Principal"), have executed an agreement for work consisting of, but not limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all grading, roads, paving, curbs and gutters, pathways, storm drains, sanitary sewers, utilities, drainage facilities, traffic controls, landscaping, street lights, and all other required facilities for Parcel/Tract Map No. 54057-3 ("Public Improvements"); WHEREAS, the Public Improvements to be performed by Principal are more particularly set forth in that certain Agreement for Completion of Pubic Improvements dated ("Improvement Agreement"); WHEREAS, the Improvement Agreement is hereby referred to and incorporated herein by reference; and WHEREAS, Principal is required to furnish a bond in connection with the Improvement Agreement providing that if Principal or any of its subcontractors shall fail to pay for any materials, provisions, or other supplies, or terms used in, upon, for, or about the performance of the Public Improvements, or for any work or labor done thereon of any kind, or for amounts due under the provisions of Title 15 (commencing with section 3082) of Part 4 of Division 3 of the California Civil Code, with respect to such work or labor, that the Surety on this bond will pay the same together with a reasonable attorney's fee in case suit is brought on the bond. Philadelphia Indemnity Insurance Company NOW, THEREFORE, Principal and (`'Surety"), a corporation organized and existing under the laws of the State of Pennsylvania , and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto City and to any and all material men, persons, companies or corporations furnishing materials, provisions, and other supplies used in, upon, for or about the performance of the Public Improvements, and all persons, companies or corporations renting or hiring teams, or implements or macl-finely, for or contributing to the Public Improvements to be done, and all persons performing work or labor upon the same and all persons supplying both work and materials as aforesaid excepting the Principal, the sum of ** DOLLARS, ORANGEWMARM4EM3457. 120 **Seven Hundred Fifty -Nine Thousand Nine Hundred and no/100** Payment Bond No. PB03010400709 Page Two (2) 0 ($ 759,900-00-- ), said sum being not less than 100% of the total cost of the Public Improvements under the terms of the Improvement Agreement, we bind ourselves, our heirs, executors and administrators, successors and assigns jointly and severalty, firmly by these presents. ME CONDITION OF THIS OBLIGATION IS SUCH that if the Principal, his or its subcontractors, hews, executors, administrators, successors, or assigns, shall fail to pay for any materials, provisions, or other supplies or machinery used in, upon, for or about the performance of the Public Improvements, or for work or labor thereon of any kind, or fail to pay any of the persons named in California Civil Code Section 3181, or amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such claimant, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and his subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor, and all other applicable laws of the State of California and rules and regulations of its agencies, then said Surety will pay the same in or to an amount not exceeding the sum specified herein. As part of the obligation secured hereby, and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. This bond is executed and filed to comply with Section 66499 et sem. of the California Government Code as security for payment to contractors, subcontractors, and persons furnishing labor, materials, or equipment for construction of the Public Improvements or performance of the Improvement Agreement. It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the California Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the Improvement Agreement, or to any plans, profiles, and specifications related thereto, or to the Public Improvements to be constructed thereunder, shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition. ORANGEIMMARTH,MM3457. 120 Payment Bond No. PB03010400709 Page Three (3) IN WITNESS WHEREOF, the seal and signature of the Principal is hereto affixed, and the corporate seal and the name of the Surety is hereto affixed and attested by its duly authorized Attorney -in -Fact at !Irvine, California this 29th day of April , 2013 . TRI Pointe Homes, Inc., a Delaware corporation Philadelphia Indemnity Insurance Company Principal President NOTE: Attorney -in -Fact `I r`o mkSy, 1 I { nina Monroe (print name) (print name) APPROPRIATE NOTARIAL ACKNOWLEDGMENTS OF EXECUTION BY PRINCIPAL AND SURETY, AND A COPY OF THE POWER OF ATTORNEY TO LOCAL REPRESENTATIVES OF THE BONDING COMPANY MUST BE ATTACHED TO THIS BOND. ORANGB2v1MAWIINEW3457. 120 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of _ 0 r�, On t;- Z () before me, r V G ���� 1 l �� �� V rw I DWS r Insert Name and Title cf the Qlflcer personally appeared J. WAFID Commission # 1973102 Notary Public - California z prangs County n Comm. I x 'Its is Mar 24, 2016 CIVIL CODE § 1189 who proved to me on the basis of satisfactory evidence to be the person.(s)'whose name(.$)-is/are subscribed to the within instrument and acknowledged to me that he/shelthey' executed the same in his/heiAheir authorized capacity(ies), and that by his/her/their- signatureaKon the instrument the perso*y, or the entity upon behalf of which the person(s)�acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: (MAt Place Notary Seal Above q ® Signalure of Notary Public OPTI®IV/'iL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date. Number of Pages:: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual M. ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing Signer's Name: ❑ Corporate Officer — Title(s): ❑ Individual ❑ Partner — ❑ Limited ❑ General Top of thumb here ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 0 2010 National Notary Association • NationalNotary.org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 CALIFORNIA ALL—PURPOSE ACKNOWLEDGMENT STATE OF CALIFORNIA County of Orange On APR 2 9 2013 before me, Michelle Haase Date Insert Name of Notary exactly as it appears on the official seal personally appeared Janina Monroe Name(s) of Signer(s) MICHELLE HAASE CaMMIssion # 1986148 Z Notary Public - California zZ ®range County r MY Comm. Ex fres Aug22, 2016 , Notary Public, who proved to me on the basis of satisfactory evidence to be the person/, whose nameM is/W- subscribed to the within instrument and acknowledged to me thatft/she/tbOjo executed the same in M/herltt'1[3(r authorized capacity(ioW, and that by k*/her/tWr signature* on the instrument the personM, or the entity upon behalf of which the person(( acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and official eal. Signature Place Notary Seal Above Sign alu a of Nolary Public OPTIONAL Though the information below is not required by law it niay prove valuable to persons relying on the document and could prevent fraudulent removal anJ reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name - F1 Individual ❑ Corporate Officer—Title(s):_ ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attomey in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing. 166 PHILADELPHIA INDEMNITY INSURANCE COMPANY 47 231 St. Asaph's Rd., Suite 100 Bala Cynwyd, PA 19004-0950 Power of Attorney KNOW ALL PERSONS BY THESE PRESENTS: that PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and appoint: JANINA MONROE, THOMAS G. MCCALL, TIMOTHY J. NOONAN AND MICHELLE HAASE OF LOCKTON COMPANIES, LLC; its true and lawful Attorney(s) in fact with full authority to execute on its behalf bonds, undertakings, recognizances and other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to exceed $5,000,000.00: This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PHILADELPHIA INDEMNITY INSURANCE COMPANY at a meeting duly called the V day of July, 2011. RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the Company to: (l) Appoint Attorney(s) in Fact and authorize [lie Attorney(s) in Fact to execute on behalf of the Company bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof and to attach the seal of the Company thereto; and (2) to remove, at any time, any such Attomey-in-Fact and revoke the authority given. And, be it FURTHER RESOLVED, neat the signatures of such officers and the seal of the Company may be affixed to any such Power of Attorney or certificate relating thereto by facsimile, and any such Power of Attorney so executed and certified by facsimile signatures and facsimile seat shall be valid and biding upon the Company in the future with the respect to any bond or undertaking to which it is attached. IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS 15TH DAY OF NOVEMBER 2012. • .. 14 (Seat) •" President Sean S. Sweeney, President Philadelphia Indemnity Insurance Company On this 150' day of November 2012. before me came the individual who executed the preceding instrument, to me personally known, and being by me duly swam said that he is the therein described and authorized officer of the PHILADELPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. G2M0 WEAL pPPENNSYLVAMIA NOTARIAL SEAL OANELLE PORATH, Natery PA k Low Kerion Tv, .,!k or� County 2010 � Notary Public: residing at: (Notary Seal) My commission expires: &jA _& k—_ Bala Cynwyd. PA March 22 2016 I, Craig P. Keller, Executive Vice President, Chief Financial Officer and Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto are true and correct and are still in full force and effect. I do further certify that Sean S. Sweeney, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHILADELPHIA INDEMNITY INSURANCE COMPANY, �PR 2 g 2013 20 In Testimony Whereof I have "subscribed my name and affixed the facsimile seal of each Company this; I day of L Craig P. Keller, Executive Vice President, Chief Financial Officer & Secretary PHILADELPHIA INDEMNITY INSURANCE COMPANY